Riskinhousingandrealestate projectsinnepalandroleofcadastralsurvey
0 likes27 views
Risk identification is important for all Housing and Real estate projects among various risks cadastral survey risk is one, which play important role during land purchasing, pooling, plotting and laying out the project. This is significant on especially in multicultural communities like Nepalese society. It includes identification of cadastral survey risks and probable disputes among neighbor regarding the border line of the land and question about laying down the construction projects. It is important to minimize those problems for successful project delivery and increase the profitability of the project. Objective of this paper is to identify the cadastral risks and find the dispute of the housing and the real estate projects. This research present the survey and analysis and conclusion based on the response.
1 of 10
Download to read offline
Recommended
determinantspaper.pdf
determinantspaper.pdfmvsa2
油
The document discusses a research work that examines the determinants of urban form and the evolution of settlements. It was authored by Sakshi Sahni and Karamjit Singh Chahal of Guru Nanak Dev University. The authors' profiles provide their publication histories and details about related projects they are working on, including one called "it was a reseach work". The document also includes links to view publication stats for the cited work.Keynote at DrupalCamp MANILA - Integration, should you do it ?
Keynote at DrupalCamp MANILA - Integration, should you do it ?Arradi Nur Rizal
油
The presentation is presented in Manila Philippine as a keynote. The topic is about system integration and the state of Drupal 8 related to its integration capabilities Anshul resume
Anshul resumeAnshul Gera
油
Experienced Software Engineer with a demonstrated history of working in the computer software industry. Skilled in Java, Python, Javascript(ES6), Flask, React and Databases. Strong engineering professional with B.Tech in Computer Engineering from Thapar University, Patiala. OSS Projects Knowledge Mining with CROSSMINER, OW2con'18, June 7-8, 2018
OSS Projects Knowledge Mining with CROSSMINER, OW2con'18, June 7-8, 2018OW2
油
CROSSMINER is an EU-funded project that mines data from various sources like source code, documentation, and configuration files to build a knowledge base. It provides recommendations to users through IDE plugins and web dashboards. The project continues the work of the OSSMETER project and involves research teams from Europe developing tools like CrossSim for detecting similar projects and CrossRec for library recommendations.Technology evangelist 101
Technology evangelist 101Sarmad Ibrahim
油
This document appears to be a log or update from a Technology Evangelist at IBM covering their activities in September 2018. It lists various events attended and supported, including an event on artificial intelligence for fashion startups, lunch and learn sessions, meetings with fashion startups and Communitech, reviewing a website, and volunteering to present at an IBM lab on their innovation program. It also references badges achieved and supporting teams for an aquahacking final event.PyQtGraph evening
PyQtGraph eveningTeachHindi
油
Aditya Kelekar talks about open source development for non programmers at Tiedekulma, Helsinki on 20.5.2018Towards Better Open-Source Development:
Towards Better Open-Source Development:TeachHindi
油
This document discusses improving the feature development process for the open-source PyQtGraph library. It first provides background on PyQtGraph and open-source development practices. It then analyzes PyQtGraph's current process through case studies and identifies areas for improvement, such as needing a collaboration tool to better coordinate contributions. The document proposes extending the "Pirate Metrics" framework to better measure community interactions during feature development. The conclusions note this study could help developers, maintainers, and users better understand open-source processes.Innovationconference
InnovationconferenceJuana Abetria
油
This document discusses a program that uses artificial neural networks to predict delays, additional time requirements, and cost overruns on construction projects, especially emergency reconstruction projects. The program aims to analyze risks in a project before deadlines and funding shortages to better manage schedules and budgets. The author is Dr. Rasha A Waheeb from the Norwegian University of Science and Technology, and their work on this program is related to other projects involving concrete design and emergency reconstruction project risk management.悋惺悋 悋悽惠惶惘悸 悴悋惠 Abbreviations of Journals Titles
悋惺悋 悋悽惠惶惘悸 悴悋惠 Abbreviations of Journals TitlesAli I. Al-Mosawi
油
惓惘 悋悖忰悋 惠愀惡 悋悴悋惠 悋惡悋忰惓 惠惘惠惡 惶悋惆惘 悋悋惠 惡忰惓 惠 惺悋 悋悴悋惠 悽惠惶惘悸 悖 惡惆 悵惘 悋惺悋 悋悋 悋. 悋忰惶 惺 悵悋 惺悋 悽惠惶惘悸 悋惺 惺惆惆悸 惠悴惆 悖愆惘悋 惆惘悴悸 悵悋 悋惠惘惘.Mumbai megaproject relocating_the_indian_navy_outside_mumbai
Mumbai megaproject relocating_the_indian_navy_outside_mumbaiMumbai_Megaproject
油
This document provides an overview and introduction to a project proposal called the "Creation of a Norflok Lookalike". It discusses the organizations involved in the project - Busybric Infrastructure and The Nataraja Foundation. It also mentions that the project details will be shared with interested parties who sign confidentiality agreements and project agreements. The document continues with short biographies of the authors and an acknowledgments section recognizing contributions from other individuals and organizations.Mumbai megaproject contracts_and_commercial_execution_strategy
Mumbai megaproject contracts_and_commercial_execution_strategyMumbai_Megaproject
油
This document discusses the contracts and commercial execution strategy for the Mumbai Megaproject. Key points include:
1. The strategy aims to ensure transparency and accountability to prevent fraud and ambiguity.
2. The city will be divided into 72 contractor territories awarded to 12 large EPC companies through a competitive bidding process.
3. A three-stage bidding process includes an initial design competition, then a peer review, and finally a construction contract award.
4. Procurement will utilize local sub-contractors and international contractors to ensure quality, and use centralized booking of plant capacities to lower costs. Training centers will also be required to develop local skills.Final digital-citzenship
Final digital-citzenshipMariam Bouls
油
This document discusses developing standards for digital citizenship education and applications in school curricula. It is a conference paper by Sobhy Sharaf and Mohamed El-Demerdash from Minoufiya University discussing how to educate students on digital citizenship and its applications in school curricula. The authors are also working on other related projects involving developing geometric creativity and the MC2 project.Delay Analysis of National Highway NH 44 Using Primavera Software
Delay Analysis of National Highway NH 44 Using Primavera Softwareijtsrd
油
Nowadays the planned duration is one of the main criteria when judging whether a construction project is a failure or not. Additionally, construction designing is claimed to achieve success if the project completes inside the planned duration or if it identifies a problem well prior to, thereby alerting the project management team to resolve the problem before it causes any impact on the completion date. This analysis of the National Highway Dewas Ujjain delay factors was investigated. Participant observation was adopted an approach has advised that from the descriptive principles of anthropology Success factors related to say and. It is argued that this project a shadow culture exists among participants, an embedded interactive supervisor perspective angle just clear that was found. Designing method and its effectiveness planning this shadow culture within the team and immediately the quality of relationships between the stakeholders associated with human difference management serves to modify. The analysis concludes by questioning the parable amongst project participants that construction coming up with could be a mechanistic method that has got to be conducted entirely by the look team. Indrajeet Kumar | Afzal Khan "Delay Analysis of National Highway NH-44 Using Primavera Software" Published in International Journal of Trend in Scientific Research and Development (ijtsrd), ISSN: 2456-6470, Volume-8 | Issue-2 , April 2024, URL: https://www.ijtsrd.com/papers/ijtsrd64558.pdf Paper Url: https://www.ijtsrd.com/engineering/civil-engineering/64558/delay-analysis-of-national-highway-nh44-using-primavera-software/indrajeet-kumar
AmmonsRoenigk.2022.Cause-and-EffectDiagrams.pdf
AmmonsRoenigk.2022.Cause-and-EffectDiagrams.pdfEKOSETIAWAN731384
油
This document discusses cause-and-effect diagrams and is an excerpt from a chapter in a book published in July 2021. It has been viewed 82 times and was authored by David N. Ammons and Dale J. Roenigk from the University of North Carolina at Chapel Hill, who have also worked on related projects involving citizen-assisted performance measurement and local government financial condition.Rja7 la educacion en la nube importante
Rja7 la educacion en la nube importantetpc_p4b
油
Cloud education provides a new environment for distance education in the 21st century. It allows educational resources to be accessed from anywhere using internet connected devices. This helps address issues of access in remote areas and promotes flexible, personalized and collaborative learning. Cloud services can be used to develop virtual classrooms, sharing of educational content and tools, as well as communication between teachers and students. Overall, cloud education helps modernize distance learning through the effective use of technology.The giant offshore_landfill_project
The giant offshore_landfill_projectMumbai_Megaproject
油
This document provides an overview and introduction to "The Giant Offshore Landfill Project" which is part of a larger initiative called "The Mumbai Megaproject". It describes the organizations involved in the project - Busybric Infrastructure and The Nataraja Foundation. It also provides brief biographies of the authors and acknowledges contributions from various individuals and organizations that helped inform the project design. The document is a copyrighted material and requests written permission to reproduce any part of the publication. It directs interested readers to contact the Planning and Design Lab for more information about the project.The dharavi inclusive_re-development_scheme
The dharavi inclusive_re-development_schemeMumbai_Megaproject
油
The document outlines a proposed redevelopment scheme for Dharavi in Mumbai, India. It discusses previous failed redevelopment efforts and proposes an alternative "inclusive" scheme from the Mumbai Megaproject. Key points of the new proposal include developing the area in phases over 6-7 years while minimizing disruption, basing redevelopment on more recent demographic studies, offering housing and community options, and using improved project management. The proposal aims to fully involve local cooperatives and residents to succeed where previous top-down schemes had failed. Project details will be shared with interested partners pending legal processes.The kuber heights_financial_centre
The kuber heights_financial_centreMumbai_Megaproject
油
The document discusses plans for a proposed "Kuber Heights Financial Centre" as part of the larger Mumbai Megaproject. It will include India's first "supertall" skyscraper to develop local construction expertise. Financing will support tiger conservation efforts, providing Rs. 200 crores annually. A design competition will engage global experts and the winning design will undergo review before construction. Project details will be shared with partners after a legal process.
Mumbai megaproject new_undersea_subway_ring
Mumbai megaproject new_undersea_subway_ringMumbai_Megaproject
油
The document proposes an underwater subway ring concept for Mumbai to address issues with the current overloaded public transport system. The proposed 210 km underground metro network would reduce traffic on local trains by 60% and replace monorail systems. The entire network would be built within 7 years by multiple contractors to allow passengers within 10 minutes of a station. A substantial portion of the project costs would be financed through the unique PPP framework proposed by the Mumbai Megaproject.STI 2022 - Generating large-scale network analyses of scientific landscapes i...
STI 2022 - Generating large-scale network analyses of scientific landscapes i...Michele Pasin
油
The growth of large, programatically accessible bibliometrics databases presents new opportunities for complex analyses of publication metadata. In addition to providing a wealth of information about authors and institutions, databases such as those provided by Dimensions also provide conceptual information and links to entities such as grants, funders and patents. However, data is not the only challenge in evaluating patterns in scholarly work: These large datasets can be challenging to integrate, particularly for those unfamiliar with the complex schemas necessary for accommodating such heterogeneous information, and those most comfortable with data mining may not be as experienced in data visualisation. Here, we present an open-source Python library that streamlines the process accessing and diagramming subsets of the Dimensions on Google BigQuery database and demonstrate its use on the freely available Dimensions COVID-19 dataset. We are optimistic that this tool will expand access to this valuable information by streamlining what would otherwise be multiple complex technical tasks, enabling more researchers to examine patterns in research focus and collaboration over time.Project Management, Perspective, Planning And Implementation
Project Management, Perspective, Planning And ImplementationCamella Taylor
油
Project planning is key to a project's success. It involves defining the project, developing a work breakdown structure that outlines all tasks and subtasks, and creating schedules, budgets, and quality plans. Effective project planning requires identifying roles and responsibilities, establishing communication plans, and considering risks and constraints. Careful planning helps ensure projects are completed on time, on budget, and to a high quality.Mumbai megaproject support_infrastructure
Mumbai megaproject support_infrastructureMumbai_Megaproject
油
The document discusses plans to support infrastructure creation for a large megaproject in Mumbai, India. It proposes strategic investments in training institutions, cement and steel supply chains, special building materials, power plants, construction equipment, and project consulting to help execute the megaproject quickly and reduce costs substantially. The goal is to commit to capital expenditures of Rs. 300-400 crores daily during peak construction in a way that accesses critical manufacturing and service capacities globally and within Maharashtra to complete the project on time and on budget. Project procurement concepts will be discussed with prospective partners and local government through a legally documented process.Investigating the Effectiveness of Construction Practices in Delayed Resident...
Investigating the Effectiveness of Construction Practices in Delayed Resident...ijtsrd
油
Construction schedule delays could also be explained by means of the late completion of construction add comparison of designed schedule of project. If the explanations of the development projects schedule delay are found then the project schedule delay in construction may be reduced. During this study, factors of schedule delay were selected after the past review of literature then arranged them in primary sets. On following the survey outcomes, the highest causative groups and factors that require more consideration of delays in kokan region were explained. Satej R. Desai | A. T. Pawar "Investigating the Effectiveness of Construction Practices in Delayed Residential Projects in Gadhinglaj City through Time and Cost Perspective" Published in International Journal of Trend in Scientific Research and Development (ijtsrd), ISSN: 2456-6470, Volume-4 | Issue-3 , April 2020, URL: https://www.ijtsrd.com/papers/ijtsrd30530.pdf Paper Url :https://www.ijtsrd.com/engineering/civil-engineering/30530/investigating-the-effectiveness-of-construction-practices-in-delayed-residential-projects-in-gadhinglaj-city-through-time-and-cost-perspective/satej-r-desai
Mumbai megaproject east_central_park
Mumbai megaproject east_central_parkMumbai_Megaproject
油
This document provides an overview of the proposed East Central Park project in Mumbai, India. The park would stretch 18 kilometers from Mahul to the Gateway of India, making it one of the largest city parks globally. It would occupy 400 meters of land vacated by relocated factories and ports. The park aims to be a shared cultural and recreation center for Mumbai residents, on par with major world-class parks. Project details will be shared with interested parties after completing legal processes.Clinical pharmacy services and pharmaceutical care in the emergency departmen...
Clinical pharmacy services and pharmaceutical care in the emergency departmen...M. Luisetto Pharm.D.Spec. Pharmacology
油
Clinical pharmacy services and pharmaceutical care in the Emergency department 2020 discusses providing clinical pharmacy services in emergency departments to optimize medication management and improve patient outcomes. The book was authored by Ghulam Rasool Mashori, Behzad Nili, and others in December 2019 and discusses strategies for medication reconciliation, adverse drug reaction identification and management, and reducing medication errors in emergency care settings. Some of the authors are also working on related projects involving healthcare management strategies and imaging applications for clinical pharmacists.The inner harbour_redevelopment_concept
The inner harbour_redevelopment_conceptMumbai_Megaproject
油
This document provides an overview of the Eastern Seaboard Redevelopment Concept project. It acknowledges that Busybric Infrastructure and The Nataraja Foundation own the project design and have assigned further development to The Planning and Design Lab. It introduces the authors and acknowledges contributions from others to the project proposal. The document notes that project details will be shared subject to a confidentiality agreement and fees.PMC2
PMC2PMI2011
油
This document discusses a case study of a gas turbine engine development project by the Gas Turbine Research Establishment (GTRE) in India. The project required managing many stakeholders, including the Indian Air Force, certification authorities, industries, and academic institutions. GTRE identified stakeholders at different phases of the project and kept them informed of progress and issues. Managing stakeholder expectations, resolving conflicts, and gaining support and resources from stakeholders were critical to the project's success. The collaboration with stakeholders helped build technical capabilities within GTRE and Indian industries.Urbandevelopment projectsandrisksmanagement
Urbandevelopment projectsandrisksmanagementDr.Madhav Prasad Koirala
油
Engineering management to urban development, particularly construction projects are
usually considered a high risk job mostly because of, a lack of adequate governments act
with necessary policies, environmental information, and urban construction experiences.
Similar construction projects may have very different risk characteristics of different
development regions in Nepal. It is difficult for a newcomer to identify new risks, in a new
environment and politically instable in the country. It is more difficult to assess these risks
and impact of relationships among them. On the one hand, ignoring these risks is
irresponsible and unrealistic decisions by the professionals. On the other hand, identifying
and assessing all the new risks and their relationships is a very complicated, time-consuming,
and expensive process. This process is possible for the majority of projects, especially when
there are adequate amounts of information, skilled technical team, and enough time. When
such a complex scenario faced the accessing and responding these vital risk factors in urban
development projects becomes extremely important. Engineering knowledge is the basic tools
to apply for drastic change in the country's infrastructures for urban development.Riskanalysisin housingindustry (1)
Riskanalysisin housingindustry (1)Dr.Madhav Prasad Koirala
油
The occupational accidents are not standardized. Particularly, developing countries do not have
guided information on their accidents due to safety, health and environment which are lack of
proper systems. The number of accidents occurring in each project are not projected and
published in Nepal. Training, awarding for the workers is not done or not effective. Safety
engineers along with the workers need to aware to every project is not yet started. Project owner,
consultant and contractors must be responsible along with the construction safety Act which
must be promulgated as soon as possible to response the risk.More Related Content
Similar to Riskinhousingandrealestate projectsinnepalandroleofcadastralsurvey (20)
悋惺悋 悋悽惠惶惘悸 悴悋惠 Abbreviations of Journals Titles
悋惺悋 悋悽惠惶惘悸 悴悋惠 Abbreviations of Journals TitlesAli I. Al-Mosawi
油
惓惘 悋悖忰悋 惠愀惡 悋悴悋惠 悋惡悋忰惓 惠惘惠惡 惶悋惆惘 悋悋惠 惡忰惓 惠 惺悋 悋悴悋惠 悽惠惶惘悸 悖 惡惆 悵惘 悋惺悋 悋悋 悋. 悋忰惶 惺 悵悋 惺悋 悽惠惶惘悸 悋惺 惺惆惆悸 惠悴惆 悖愆惘悋 惆惘悴悸 悵悋 悋惠惘惘.Mumbai megaproject relocating_the_indian_navy_outside_mumbai
Mumbai megaproject relocating_the_indian_navy_outside_mumbaiMumbai_Megaproject
油
This document provides an overview and introduction to a project proposal called the "Creation of a Norflok Lookalike". It discusses the organizations involved in the project - Busybric Infrastructure and The Nataraja Foundation. It also mentions that the project details will be shared with interested parties who sign confidentiality agreements and project agreements. The document continues with short biographies of the authors and an acknowledgments section recognizing contributions from other individuals and organizations.Mumbai megaproject contracts_and_commercial_execution_strategy
Mumbai megaproject contracts_and_commercial_execution_strategyMumbai_Megaproject
油
This document discusses the contracts and commercial execution strategy for the Mumbai Megaproject. Key points include:
1. The strategy aims to ensure transparency and accountability to prevent fraud and ambiguity.
2. The city will be divided into 72 contractor territories awarded to 12 large EPC companies through a competitive bidding process.
3. A three-stage bidding process includes an initial design competition, then a peer review, and finally a construction contract award.
4. Procurement will utilize local sub-contractors and international contractors to ensure quality, and use centralized booking of plant capacities to lower costs. Training centers will also be required to develop local skills.Final digital-citzenship
Final digital-citzenshipMariam Bouls
油
This document discusses developing standards for digital citizenship education and applications in school curricula. It is a conference paper by Sobhy Sharaf and Mohamed El-Demerdash from Minoufiya University discussing how to educate students on digital citizenship and its applications in school curricula. The authors are also working on other related projects involving developing geometric creativity and the MC2 project.Delay Analysis of National Highway NH 44 Using Primavera Software
Delay Analysis of National Highway NH 44 Using Primavera Softwareijtsrd
油
Nowadays the planned duration is one of the main criteria when judging whether a construction project is a failure or not. Additionally, construction designing is claimed to achieve success if the project completes inside the planned duration or if it identifies a problem well prior to, thereby alerting the project management team to resolve the problem before it causes any impact on the completion date. This analysis of the National Highway Dewas Ujjain delay factors was investigated. Participant observation was adopted an approach has advised that from the descriptive principles of anthropology Success factors related to say and. It is argued that this project a shadow culture exists among participants, an embedded interactive supervisor perspective angle just clear that was found. Designing method and its effectiveness planning this shadow culture within the team and immediately the quality of relationships between the stakeholders associated with human difference management serves to modify. The analysis concludes by questioning the parable amongst project participants that construction coming up with could be a mechanistic method that has got to be conducted entirely by the look team. Indrajeet Kumar | Afzal Khan "Delay Analysis of National Highway NH-44 Using Primavera Software" Published in International Journal of Trend in Scientific Research and Development (ijtsrd), ISSN: 2456-6470, Volume-8 | Issue-2 , April 2024, URL: https://www.ijtsrd.com/papers/ijtsrd64558.pdf Paper Url: https://www.ijtsrd.com/engineering/civil-engineering/64558/delay-analysis-of-national-highway-nh44-using-primavera-software/indrajeet-kumar
AmmonsRoenigk.2022.Cause-and-EffectDiagrams.pdf
AmmonsRoenigk.2022.Cause-and-EffectDiagrams.pdfEKOSETIAWAN731384
油
This document discusses cause-and-effect diagrams and is an excerpt from a chapter in a book published in July 2021. It has been viewed 82 times and was authored by David N. Ammons and Dale J. Roenigk from the University of North Carolina at Chapel Hill, who have also worked on related projects involving citizen-assisted performance measurement and local government financial condition.Rja7 la educacion en la nube importante
Rja7 la educacion en la nube importantetpc_p4b
油
Cloud education provides a new environment for distance education in the 21st century. It allows educational resources to be accessed from anywhere using internet connected devices. This helps address issues of access in remote areas and promotes flexible, personalized and collaborative learning. Cloud services can be used to develop virtual classrooms, sharing of educational content and tools, as well as communication between teachers and students. Overall, cloud education helps modernize distance learning through the effective use of technology.The giant offshore_landfill_project
The giant offshore_landfill_projectMumbai_Megaproject
油
This document provides an overview and introduction to "The Giant Offshore Landfill Project" which is part of a larger initiative called "The Mumbai Megaproject". It describes the organizations involved in the project - Busybric Infrastructure and The Nataraja Foundation. It also provides brief biographies of the authors and acknowledges contributions from various individuals and organizations that helped inform the project design. The document is a copyrighted material and requests written permission to reproduce any part of the publication. It directs interested readers to contact the Planning and Design Lab for more information about the project.The dharavi inclusive_re-development_scheme
The dharavi inclusive_re-development_schemeMumbai_Megaproject
油
The document outlines a proposed redevelopment scheme for Dharavi in Mumbai, India. It discusses previous failed redevelopment efforts and proposes an alternative "inclusive" scheme from the Mumbai Megaproject. Key points of the new proposal include developing the area in phases over 6-7 years while minimizing disruption, basing redevelopment on more recent demographic studies, offering housing and community options, and using improved project management. The proposal aims to fully involve local cooperatives and residents to succeed where previous top-down schemes had failed. Project details will be shared with interested partners pending legal processes.The kuber heights_financial_centre
The kuber heights_financial_centreMumbai_Megaproject
油
The document discusses plans for a proposed "Kuber Heights Financial Centre" as part of the larger Mumbai Megaproject. It will include India's first "supertall" skyscraper to develop local construction expertise. Financing will support tiger conservation efforts, providing Rs. 200 crores annually. A design competition will engage global experts and the winning design will undergo review before construction. Project details will be shared with partners after a legal process.Mumbai megaproject new_undersea_subway_ring
Mumbai megaproject new_undersea_subway_ringMumbai_Megaproject
油
The document proposes an underwater subway ring concept for Mumbai to address issues with the current overloaded public transport system. The proposed 210 km underground metro network would reduce traffic on local trains by 60% and replace monorail systems. The entire network would be built within 7 years by multiple contractors to allow passengers within 10 minutes of a station. A substantial portion of the project costs would be financed through the unique PPP framework proposed by the Mumbai Megaproject.STI 2022 - Generating large-scale network analyses of scientific landscapes i...
STI 2022 - Generating large-scale network analyses of scientific landscapes i...Michele Pasin
油
The growth of large, programatically accessible bibliometrics databases presents new opportunities for complex analyses of publication metadata. In addition to providing a wealth of information about authors and institutions, databases such as those provided by Dimensions also provide conceptual information and links to entities such as grants, funders and patents. However, data is not the only challenge in evaluating patterns in scholarly work: These large datasets can be challenging to integrate, particularly for those unfamiliar with the complex schemas necessary for accommodating such heterogeneous information, and those most comfortable with data mining may not be as experienced in data visualisation. Here, we present an open-source Python library that streamlines the process accessing and diagramming subsets of the Dimensions on Google BigQuery database and demonstrate its use on the freely available Dimensions COVID-19 dataset. We are optimistic that this tool will expand access to this valuable information by streamlining what would otherwise be multiple complex technical tasks, enabling more researchers to examine patterns in research focus and collaboration over time.Project Management, Perspective, Planning And Implementation
Project Management, Perspective, Planning And ImplementationCamella Taylor
油
Project planning is key to a project's success. It involves defining the project, developing a work breakdown structure that outlines all tasks and subtasks, and creating schedules, budgets, and quality plans. Effective project planning requires identifying roles and responsibilities, establishing communication plans, and considering risks and constraints. Careful planning helps ensure projects are completed on time, on budget, and to a high quality.Mumbai megaproject support_infrastructure
Mumbai megaproject support_infrastructureMumbai_Megaproject
油
The document discusses plans to support infrastructure creation for a large megaproject in Mumbai, India. It proposes strategic investments in training institutions, cement and steel supply chains, special building materials, power plants, construction equipment, and project consulting to help execute the megaproject quickly and reduce costs substantially. The goal is to commit to capital expenditures of Rs. 300-400 crores daily during peak construction in a way that accesses critical manufacturing and service capacities globally and within Maharashtra to complete the project on time and on budget. Project procurement concepts will be discussed with prospective partners and local government through a legally documented process.Investigating the Effectiveness of Construction Practices in Delayed Resident...
Investigating the Effectiveness of Construction Practices in Delayed Resident...ijtsrd
油
Construction schedule delays could also be explained by means of the late completion of construction add comparison of designed schedule of project. If the explanations of the development projects schedule delay are found then the project schedule delay in construction may be reduced. During this study, factors of schedule delay were selected after the past review of literature then arranged them in primary sets. On following the survey outcomes, the highest causative groups and factors that require more consideration of delays in kokan region were explained. Satej R. Desai | A. T. Pawar "Investigating the Effectiveness of Construction Practices in Delayed Residential Projects in Gadhinglaj City through Time and Cost Perspective" Published in International Journal of Trend in Scientific Research and Development (ijtsrd), ISSN: 2456-6470, Volume-4 | Issue-3 , April 2020, URL: https://www.ijtsrd.com/papers/ijtsrd30530.pdf Paper Url :https://www.ijtsrd.com/engineering/civil-engineering/30530/investigating-the-effectiveness-of-construction-practices-in-delayed-residential-projects-in-gadhinglaj-city-through-time-and-cost-perspective/satej-r-desai
Mumbai megaproject east_central_park
Mumbai megaproject east_central_parkMumbai_Megaproject
油
This document provides an overview of the proposed East Central Park project in Mumbai, India. The park would stretch 18 kilometers from Mahul to the Gateway of India, making it one of the largest city parks globally. It would occupy 400 meters of land vacated by relocated factories and ports. The park aims to be a shared cultural and recreation center for Mumbai residents, on par with major world-class parks. Project details will be shared with interested parties after completing legal processes.Clinical pharmacy services and pharmaceutical care in the emergency departmen...
Clinical pharmacy services and pharmaceutical care in the emergency departmen...M. Luisetto Pharm.D.Spec. Pharmacology
油
Clinical pharmacy services and pharmaceutical care in the Emergency department 2020 discusses providing clinical pharmacy services in emergency departments to optimize medication management and improve patient outcomes. The book was authored by Ghulam Rasool Mashori, Behzad Nili, and others in December 2019 and discusses strategies for medication reconciliation, adverse drug reaction identification and management, and reducing medication errors in emergency care settings. Some of the authors are also working on related projects involving healthcare management strategies and imaging applications for clinical pharmacists.The inner harbour_redevelopment_concept
The inner harbour_redevelopment_conceptMumbai_Megaproject
油
This document provides an overview of the Eastern Seaboard Redevelopment Concept project. It acknowledges that Busybric Infrastructure and The Nataraja Foundation own the project design and have assigned further development to The Planning and Design Lab. It introduces the authors and acknowledges contributions from others to the project proposal. The document notes that project details will be shared subject to a confidentiality agreement and fees.PMC2
PMC2PMI2011
油
This document discusses a case study of a gas turbine engine development project by the Gas Turbine Research Establishment (GTRE) in India. The project required managing many stakeholders, including the Indian Air Force, certification authorities, industries, and academic institutions. GTRE identified stakeholders at different phases of the project and kept them informed of progress and issues. Managing stakeholder expectations, resolving conflicts, and gaining support and resources from stakeholders were critical to the project's success. The collaboration with stakeholders helped build technical capabilities within GTRE and Indian industries.Clinical pharmacy services and pharmaceutical care in the emergency departmen...
Clinical pharmacy services and pharmaceutical care in the emergency departmen...M. Luisetto Pharm.D.Spec. Pharmacology
油
More from Dr.Madhav Prasad Koirala (13)
Urbandevelopment projectsandrisksmanagement
Urbandevelopment projectsandrisksmanagementDr.Madhav Prasad Koirala
油
Engineering management to urban development, particularly construction projects are
usually considered a high risk job mostly because of, a lack of adequate governments act
with necessary policies, environmental information, and urban construction experiences.
Similar construction projects may have very different risk characteristics of different
development regions in Nepal. It is difficult for a newcomer to identify new risks, in a new
environment and politically instable in the country. It is more difficult to assess these risks
and impact of relationships among them. On the one hand, ignoring these risks is
irresponsible and unrealistic decisions by the professionals. On the other hand, identifying
and assessing all the new risks and their relationships is a very complicated, time-consuming,
and expensive process. This process is possible for the majority of projects, especially when
there are adequate amounts of information, skilled technical team, and enough time. When
such a complex scenario faced the accessing and responding these vital risk factors in urban
development projects becomes extremely important. Engineering knowledge is the basic tools
to apply for drastic change in the country's infrastructures for urban development.Riskanalysisin housingindustry (1)
Riskanalysisin housingindustry (1)Dr.Madhav Prasad Koirala
油
The occupational accidents are not standardized. Particularly, developing countries do not have
guided information on their accidents due to safety, health and environment which are lack of
proper systems. The number of accidents occurring in each project are not projected and
published in Nepal. Training, awarding for the workers is not done or not effective. Safety
engineers along with the workers need to aware to every project is not yet started. Project owner,
consultant and contractors must be responsible along with the construction safety Act which
must be promulgated as soon as possible to response the risk.Infrastructure constructin risk
Infrastructure constructin riskDr.Madhav Prasad Koirala
油
In this chapter, it is discuss the risk factors involved in infrastructure construction
projects. Under the theoretical Perspective model, following topics are being
discussed: Introduction, Infrastructure and urbanization in regional context,
Infrastructure and urbanization in Nepalese context, Role of infrastructure housing
apartment and real estate, Housing and real Estate in developing countries and worth
of the infrastructure projects. Finally summaries of this chapter is outlinedIjertv5 is120035 artickle
Ijertv5 is120035 artickleDr.Madhav Prasad Koirala
油
Workers' health and safety is an important asset , it enhances the productivity, efficiency, quality of every industry if well maintained. Construction material producer are vital industries from where supplying the demand of emerging construction materials to infrastructure and habitat projects as per projects' need. These industries employing lot of workers but they are not being worry about health and safety. Different convention of ILO as well as WHO have emphasizes to respond the issues related workers health and safety. Nepal had not yet ratified ILO convention No. 155 on occupational safety and health. Therefore lot of death, fatalities are suffered due to health and safety. It is important asset of workers that must be taken seriously by all stake holders as well as the nation. To make civilize society, all should be aware about every one's health and safety that too, workers health of safety is very important issues in every industry.Article 1542102220
Article 1542102220Dr.Madhav Prasad Koirala
油
All Level of government is yet to formulate legal practice of
sustainable extraction and uses of stone resources in only a few parts of
the Nepal, and there are few or no guidelines for the extraction and
uses of natural resources to follow. Nevertheless, the Stone industry
can independently utilize sustainable management techniques to
achieve the goals of meeting their needs for reserves without
compromising the ability of future generations to meet their needs.
This study includes the existing data and literature with laboratory testing for the suitability
of stone and stone byproducts for different infrastructure projects. The different quarry site of
Nepal has been identified by Department of Mines and Geology and Road Construction and
Maintenance Materials Study (RCMMS), Department of Road. For this, Kotre quarry site is
selected which is located at the boundary of Kaski and Tanahun district. As per the estimated
area of Kotre quarry is 921887.119 square meter. It is found that the quarry is recharged due
to the transportation of aggregate from Himalayan zone by flood in the monsoon season. The
properties of aggregate are tested for the quality of the aggregate and required properties is
fulfilling by this quarry. Article 10876 38133-1-pb
Article 10876 38133-1-pbDr.Madhav Prasad Koirala
油
The main purpose of this paper is identify the risks involved in housing and
real estate of construction projects in Nepal and ranks them as per the severity. In this
research, first the risks involved in construction projects life cycle has been identified
with the help of professional expertise and verified with the help of housing profession
arranged in a respondent in systematic hierarchical structure. Questionnaire surveys and
literature review were used for data collection. Next, based on the obtained data a
network was based on the statically system has been designed for the evaluation of
project risks. After data analysis, the result has been published and finally conclusion
has been drawn.Article 10.11648.j.ajce.20170503
Article 10.11648.j.ajce.20170503Dr.Madhav Prasad Koirala
油
This document summarizes a research article about risk factors that contribute to infrastructure development in Nepal. The article analyzes different risk factors like financial, economic, political and legal risks that affect infrastructure projects. It discusses how lack of proper planning and risk management leads to projects going over budget, extending timelines and reducing quality. The document also provides background on Nepal's infrastructure status, challenges in sectors like water, sanitation and irrigation. It analyzes risk identification and management techniques used to minimize risks and improve project outcomes.Article p1i4 engg full p 01-15 dr. madhav prasad koirala jun-2017 
Article p1i4 engg full p 01-15 dr. madhav prasad koirala jun-2017 Dr.Madhav Prasad Koirala
油
Sand quality and cost-effective leads infrastructure in rural villages, a fundamental questions are identification of
sources of construction sand mines, available quality and supply management how to maintain it is big challenges?
Should the license holder suppliers or a government agency above them manage the construction of the
infrastructure project? To answer this question, we surveyed all Society of Consulting Architectural and Engineering
Firms, Nepal (SCAFE) members involved in infrastructure projects, As per Federation Contractors Association of
Nepal (FCAN), Sand quarry operator, Sand suppliers and sand washing plant operators in Kathmandu valley of
Nepal. Findings clearly indicate that the most important causes were lack of proper management, awareness and
understanding, quality, test skill and knowledge with contractor, consult and other stake holders. Also government
and authority have not taken action to support legal aspects and control illegal operation as well as maintain supply
management of construction sand for infrastructure projects.33 article text-127-1-10-20181005
33 article text-127-1-10-20181005Dr.Madhav Prasad Koirala
油
The infrastructure construction sectors are usually complex. Zero risk construction projects are only an
assumption. The objective of this paper is to identify the risks factor associated with the urban infrastructure
construction projects causing delay. The research found that those risks are directly associated to clients,
contractors, sub-contractors that would cause delay in the construction work. Other factors are also
identified such as project, financial, political, technical, market risk, managerial, resource risk, and force
majeure. All risk factors affect the time, cost and quality performance of the construction project. From risk
management perspective, it is the process on which identifies the risks and analyzed with qualitatively and
quantitatively. All associated risks can treat by various mitigation processes and then mitigating method are
monitored to control the risks. Risk management distinguishes between success and failure of a project.
So, Nepal could use it effectively to meet its growing need of infrastructure and job opportunityIjertv8 is010007
Ijertv8 is010007Dr.Madhav Prasad Koirala
油
1) The document discusses risks in housing construction projects in developing countries like Nepal. It identifies a lack of management of risk factors throughout the project lifecycle as a key issue.
2) It reviews literature on identifying, assessing, ranking, and developing risk response plans for construction projects. Five main categories of risk are identified: time, cost, quality, political, and legal.
3) The author argues that to improve housing project outcomes, developers must systematically examine risks at each phase of the project lifecycle, rather than ignoring risk management. This includes identifying, analyzing, measuring, and developing responses to risks.Ijertv7 is090066
Ijertv7 is090066Dr.Madhav Prasad Koirala
油
The occupational accidents are not standardized to rating the risk factors for timely execution of infrastructures. Particularly, developing countries do not have guided information on their accidents due to safety, health and environment which are lack of proper systems. The number of accidents occurring in each infrastructures construction projects are not projected and published in Nepal. Training, awarding for the workers is not done or not effective. Safety engineers along with the workers need to aware to every construction project is not yet started. Project owner, consultant and contractors must be responsible along with the construction safety act which must be promulgated as soon as possible to response the Health, Safety and Environment risks. Safety engineering and prosperous Nepal are two side of same coin. By ignoring safety engineering to achieve prospers Nepal and happy Nepali is baseless dream .There would be lot of chances to inviting the risk factors which can lose much more.13 ijrg18 a12_1898 (1)
13 ijrg18 a12_1898 (1)Dr.Madhav Prasad Koirala
油
Nepal is beautiful country. According to new geographical structure there are six metropolitan
cities, eleven sub-metropolitan cities. Seventeen cities are already urbanized and two hundred and
seventy-six municipalities are also newly emerging cities. The objective of this research is mainly
urban infrastructure development, its challenges, explore the problems, identify defective
coordination within the interdisciplinary ministry, suggest for integrated infrastructure, to aware
risk factors associated during urban infrastructures. The methodology adopted was according to
various literature reviews and surveys conducted on the sport. Respondent were selected from
concerned authorities, this research shows everyone want affordable housing, public hospital,
school, college, university, drinking water, communication, drain and sanitation facilities and wide
road are prime needs. It was found the defective procurement policy including various risk factors,
a lack of adequate governments act with necessary policies, vision of leader is not globally
thinking and locally acting, human resource is not compatible, the poor performance of contactor
and consultant, project manager is not being professional and allocating budget is not enough,
since one authority built, immediately other authority dig the trench. if government started
integrated urban infrastructure projects would better for future and proper risk management plan
needs to establish.1153 3330-1-pb
1153 3330-1-pbDr.Madhav Prasad Koirala
油
Construction industry is one of the largest and most important industries in Nepal. Construction safety in
the industry still suffers from ignorance and lack of supervision and accident rate on construction projects
is very high. The objective of this study is to identify the awareness lunched in the construction industries
that relate to safety, problems related ergonomic health and safety, and the status of safety engineering
management as perceived by construction and consultancies to help reduction of accidents. A survey
was conducted by using a numbers of questionnaires which was distributed to 38 respondents. Analysis
of the responses found the most important factors that included: Awareness programs are lunching in
construction industries about health, safety and environment Weather Construction firms are managing
problems related ergonomic health and safety in construction sites? How well is the management of safety
engineering in construction projects by every firm of Nepal? Recently uploaded (20)
Renewable-Energy-Powering-Mozambiques-Economic-Growth.pptx
Renewable-Energy-Powering-Mozambiques-Economic-Growth.pptxRofino Licuco
油
Mozambique, a country with vast natural resources and immense potential, nevertheless faces several economic challenges, including high unemployment, limited access to energy, and an unstable power supply. Underdeveloped infrastructure has slowed the growth of industry and hampered peoples entrepreneurial ambitions, leaving many regions in the darkliterally and figuratively.
https://www.rofinolicuco.net/blog/how-renewable-energy-can-help-mozambique-grow-its-economyESIT135 Problem Solving Using Python Notes of Unit-1 and Unit-2
ESIT135 Problem Solving Using Python Notes of Unit-1 and Unit-2prasadmutkule1
油
ESIT135 Problem Solving Using Python Notes of Unit-1 and Unit-2
Common Network Architecture:X.25 Networks, Ethernet (Standard and Fast): fram...
Common Network Architecture:X.25 Networks, Ethernet (Standard and Fast): fram...SnehPrasad2
油
X.25 Networks, Ethernet (Standard and Fast): frame format and specifications, Wireless LANs 802.11x, 802.3 Bluetooth etc.
IoT-based-Electrical-Motor-Fault-Detection-System.pptx
IoT-based-Electrical-Motor-Fault-Detection-System.pptxatharvapardeshi03
油
IoT-based-Electrical-Motor-Fault-Detection-System.pptx
AIR FILTER system in internal combustion engine system.ppt
AIR FILTER system in internal combustion engine system.pptthisisparthipan1
油
air filter system in ic engine 
Taykon-Kalite belgeleri
Taykon-Kalite belgeleriTAYKON
油
Kalite Politikam脹z
Taykon elik i巽in kalite, hayallerinizi bizlerle paylat脹脹n脹z an balar. Proje 巽iziminden detaylar脹n 巽旦z端m端ne, detaylar脹n 巽旦z端m端nden 端retime, 端retimden montaja, montajdan teslime hayallerinizin ger巽ekletiini g旦rd端端n端z ana kadar ge巽en t端m aamalar脹, 巽al脹anlar脹, t端m teknik donan脹m ve 巽evreyi i巽ine al脹r KAL聴TE.AO Star Algorithm in Artificial Intellligence
AO Star Algorithm in Artificial Intellligencevipulkondekar
油
AO Star Algorithm in Artificial IntellligenceDefining the Future of Biophilic Design in Crete.pdf
Defining the Future of Biophilic Design in Crete.pdfARENCOS
油
Biophilic design is emerging as a key approach to enhancing well-being by integrating natural elements into residential architecture. In Crete, where the landscape is rich with breathtaking sea views, lush olive groves, and dramatic mountains, biophilic design principles can be seamlessly incorporated to create healthier, more harmonious living environments.
ESIT135 Problem Solving Using Python Notes of Unit-3
ESIT135 Problem Solving Using Python Notes of Unit-3prasadmutkule1
油
ESIT135 Problem Solving Using Python Notes of Unit-3 TASK-DECOMPOSITION BASED ANOMALY DETECTION OF MASSIVE AND HIGH-VOLATILITY SES...
TASK-DECOMPOSITION BASED ANOMALY DETECTION OF MASSIVE AND HIGH-VOLATILITY SES...samueljackson3773
油
The Science Information Network (SINET) is a Japanese academic backbone network for more than 800
universities and research institutions. The characteristic of SINET traffic is that it is enormous and highly
variableAI ppt on water jug problem by shivam sharma
AI ppt on water jug problem by shivam sharmaShivamSharma588604
油
this ppt is made on the topic of water jug problem.A Star Algorithm in Artificial intelligence
A Star Algorithm in Artificial intelligencevipulkondekar
油
A Star Algorithm in Artificial intelligenceDesign of cannal by Kennedy Theory full problem solved
Design of cannal by Kennedy Theory full problem solvedEr. Gurmeet Singh
油
Design of cannal by Kennedy Theory
By Er Gurmeet Singh
G.C.E.T JAMMU
CONTACT: Gurmeet.b.tech@gmail.com
Riskinhousingandrealestate projectsinnepalandroleofcadastralsurvey
- 1. See discussions, stats, and author pro鍖les for this publication at: https://www.researchgate.net/publication/281194618 Risk in housing and real estate Projects in Nepal and Role of cadastral Survey Research 揃 August 2015 DOI: 10.13140/RG.2.1.1973.4247 CITATIONS 0 READS 49 1 author: Some of the authors of this publication are also working on these related projects: Special issue on sustainable planning approaches for urban peripheries View project http://www.sciencepublishinggroup.com/journal/paperinfo?journalid=229&doi=10.11648/j.ajce.20170503.11 View project Madhav Prasad Koirala CMEC Research Pvt. LTD 23 PUBLICATIONS油油油19 CITATIONS油油油 SEE PROFILE All content following this page was uploaded by Madhav Prasad Koirala on 24 August 2015. The user has requested enhancement of the downloaded 鍖le.
- 10. View publication statsView publication stats